Service Solicited - 2026 - Idaho Power - Idaho Power Cost Quote - (ERAP) UpdatedW§POWER,a, CUSTOMER COST QUOTE FOR
An IDACORP Company IDAHO POWER FACILITIES
Customer or Project Name: CITY OF EAGLE - 4886 HWY 16 - 3PH UG REBUILD
Construction Costs
Line Installation Costs
1. Line Installation/Upgrade Charge
$294,943
2. Customer Credits (Betterment, Metering, Salvage)
$0
3. Customer Performed Construction Work Credit
$(29,138)
4. Net Line Installation Cost
$265,805
Unusual Conditions
5. Unusual Conditions
$31,806
6. Unusual Conditions Bank Letter of Credit (Only for over $10,000)
$0
7. Net Unusual Conditions
$31,806
Terminal Facilities Costs
8. Terminal Facilities
$4,041
9. Terminal Facilities Allowances
$0
10. Terminal Facilities Salvage
$(2,696)
11. Net Terminal Facilities Cost
$1,345
12. Underground Service and Attachment Charges
$0
13. Engineering Charge
$101
14. Permits
$0
15. Relocation or Removal
$14,894
16. Miscellaneous Charges/Adjustments
$0
17. Net Construction Costs (Line Items 4, 7, 11, 12, 13, 14, 15, 16)
$313,951
18. Prepaid Charges (Engineering, Permits & Right -of -Way) $4,074
19. Vested Interest Charge
$0
20. Customer Payment Due Prior to Construction Scheduling
$313,951
This cost may not include all construction costs, see page 3 if additional service charges apply.
Notes: Please note that continual supply chain issues outside of Idaho Power's control may cause a shortage of certain
materials and equipment necessary to complete the Work (as defined below) and may delay the timing of facilities being
installed/constructed. Idaho Power shall keep the customer reasonably apprised of any anticipated delays in the Work.
Customer understands that charges for relocation, transfer or removal of non -Idaho Power equipment attached to Idahc
Power facilities are not included in this Customer Cost Quote. It is the customer's responsibility to coordinate this work
with the affected utility. All charges associated with this work are the responsibility of the Customer. For utility contact
information, please call 208-388-2886.
Customer understands that Idaho Power determines the metering requirements at such time that Customer submits a
service request and requested electrical load during final design of the Project as contemplated herein.
Notice: This Customer Cost Quote shall be binding on both Idaho Power Company ("Idaho Power") and Customer for a period of 60
days from the quoted date indicated below, subject to changes in information provided by the Customer or changes in Idaho
Power's ability to obtain satisfactory rights -of -way or to comply with governmental regulations, including but not limited to the rules,
regulations, and tariffs of the Idaho Public Utilities Commission ("IPUC") and the Public Utility Commission of Oregon ("OPUC").
Customer must make payment of the quoted amount not less than (30) days prior to the start of the construction work set forth in this
agreement ("Work"). However, Idaho Power does not represent or warrant that the Work will commence within 30 days of receipt of
payment. The start of the Work is subject to Idaho Power's ability to obtain the necessary labor, materials and equipment.
Internal use Page 1 of 3
Service Request Number: Customer Account Number: Work Order Number: Design Number: Version:
00549609 2271130235 27696757 0000181333 002
The Customer acknowledges Idaho Power's Rule C (Service and Limitations), Section 7 (Right of Way) on file with the IPUC
OPUC: "The Customer shall, without cost to Idaho Power, grant Idaho Power a right-of-way for Idaho Power's lines and
apparatus across and upon the property owned or controlled by the Customer, necessary or incidental to the supplying of
Electric Service and shall permit access thereto by Idaho Power's employees at all reasonable hours." By signing this
Customer Cost Quote, Customer grants to Idaho Power a perpetual right-of-way over the Customer's property for the
installation, operation, replacement and maintenance of power facilities to provide electrical service to the Customer and any
future owners of the Customer's property.
Construction Costs available for refund
(Vested Interest limited to 5 years or 4 additional applicants)
$0
Customer Payment Due Prior to Scheduling Construction $313,951
N/A Underground Service Attachment Charges to be billed separately
�t The Customer understands that Underground Service Attachment Charges will be billed separately on the
Customer first month's power bill after service installation has been completed. In addition, the Customer has
initials reviewed and acknowledges their responsibility for these costs. Idaho and Oregon cost information are
available online at:
ID: https://docs.idahopower.com/pdfs/ServiceBilling/customerservice/newConstruction/ldahoCostlnfo.pdf
OR: https://docs.idahopower.com/pdfs/ServiceBilling/customerservice/newConstruction/OregonCostinfo.pdf
Statutory Certifications. In accordance with Idaho Code Section 67-2359, Idaho Power Company
hereby certifies that it is not currently, and for the duration of this Customer Cost Quote will not be,
owned or operated by the Government of China as defined in said code section. In accordance with
Idaho Code Section 67-2346, Idaho Power Company hereby certifies that it is not currently engaged
in, and for the duration of this Customer Cost Quote will not engage in, a boycott of goods and
services from Israel or territories under its control as defined in said code section.
Please sign and return all relevant forms along with the amount stated on the Customer
Cost Quote to:
IDAHO POWER COMPANY
10790 Franklin Rd
Boise, ID 83709
to i D6
Customer Signature Date
Idaho Power Representative Quote Date
07/31 /2026
Internal use Page 3 of 3
Service Request Number: Customer Account Number: Work Order Number: Design Number: Version:
00549609 2271130235 27696757 0000181333 002
" Idaho Power Company Page: 1
POW11M® Service Request Date: 7/31/2026
An IDACORP company
Service Request Number: 00549609
CITY OF EAGLE - 4886 HWY 16 - 3PH UG REBUILD
Work Order Number.
Request Type:
Rate Sch.:
Reply By:
Feeder:
Service Location:
Required in Service Date
Planning Center/Team:
Contact Detail:
27696757
CS
ZERO
BNLT11A
4886 HIGHWAY 16
1 /8/2026
CAPITAL
CUST CITY OF EAGLE
PO BOX 1520, EAGLE ID 83616
IPCO CASEY BELVOIR
10790 Franklin Rd, BOISE ID 83709
RFND CITY OF EAGLE
PO BOX 1520, EAGLE ID 83616
Attribute Information
RES/COM
Eng Hours: 00001
Eng Fee Amount(Att98): 101.00
Eng Fee Amount(Att16):
Eng Fee Service Agreement No:
Eng Fee Service Agreement Date:
Customer No: 2271130235
EAGLE, ID 83616
208-939-6813 eziegenfuss@cityofeagle.org
(208) 388-2910 CBelvoir@idahopower.com
208-939-6813
Service Voltage N/A
No. Of Meters
ZERO
Number of Phases 3
Meter Location
KW Motor Load:
Ct Loc
Largest Motor
Primary OH/UG
OH/UG
1 Phase KW Demand
Service OH/UG
OH/UG
3 Phase KW Demand
Sry Owner
Vested Int. Connected Load ZERO
Panel Amp Size
ZERO
Commercial Deposit Amount
Service Pole Riser
SIC Number
Description
REMOVE OVERHEAD CONDUCTORS, POLES, ETC. INSTALL NEW 1100 MCM IN EXISTING
CONDUIT, SPLICE IN EXISTING VAULTS, INSTALL NEW SWITCHGEAR, INSTALL NEW
PRIMARY RISER POLE, TRENCH NEW CONDUIT TO EXISTING VAULT, INSTALL 2" PRIMARY
BORE ACROSS NEW ROADWAY, CUSTOMER TO TRENCH FROM BORE PIT (PT #8) TO NEW PAD
MOUNT TRANSFORMER LOCATION (PT #15), TRANSFER EXISTING UNDERGOUND SERVICE
RISER AT PT#15 INTO PADMOUNT TRANSFORMER, INSTALL 2" SECONDARY RISER TO RE -
FEED EXISTING OVERHEAD SERVICE. CUSTOMER RESPONSIBLE FOR ALL STAKING AND
FINAL GRADE OF CUSTOMER TRENCH PATH. CUSTOMER RESPONSIBLE FOR ALL ROCK
TRENCH, AND ROCK HOLES.
Any changes to the project including but not limited to increases in load, timing of load schedule, location of service, and requested
voltage may result in additional c s and/or delay of service. It is necessary to communicate changes as soon as possible.
7/31 /2026
Customer Signature Date Idaho Power Representative Signature Date
0 IDAHO
R
An RDACORP Company
Customer Performed Construction Work Agreement
CITY OF EAGLE
4886 HIGHWAY 16 / EAGLE.ID83616
This Customer Performed Construction Agreement ("Agreement") is between Idaho Power Company ("Idaho Power") and
CITY OF EAGLE ("Customer"), and sets forth the terms and conditions that shall govern the Customer's Performing
a portion of the construction work ("Work") required as a part of Idaho Power's Work Order Number below.
Customer understands and agrees to the following with regards to the Work performed by the Customer under this agreement:
1 Work will be performed is marked on the Work Order Map attached hereto and is referred to as the Customer's Work Area.
2 The Work shall be performed under the direction and control of the Customer who shall be acting as an independent
contractor and not as an agent or employee of Idaho Power.
3 The Customer agrees to indemnify, defend, reimburse and hold harmless Idaho Power and its successors and their
respective directors, officers, members, employees, representatives, and agents from, for, and against any claims, allegations,
demands, damages, liens, losses, expenses, suits, actions, proceedings, judgments, liabilities, and costs of any kind
whatsoever (including attorneys' fees and expert witness fees and expenses) from third parties arising out of, or relating to,
the Work, a violation by Customer of any federal or state law, regulation, statute, or ordinance, or any breach by Customer
of this Agreement.
4 The Customer shall be responsible for the safety of all individuals near the Work site, including without limitation, the safety
of the Customer and its contractors, employees, and agents. The Customer shall take precautions for safety of, and shall
provide protection to prevent damage, injury or loss to (i) those performing labor or Work or furnishing materials or equipment
at the Work site and other persons who may be affected thereby; (ii) other property at the site or adjacent thereto, such as
trees, shrubs, lawns, walks, pavements, roadways, structures and utilities; and (iii) the work, materials, equipment, tools,
machinery and facilities of or being utilized by Idaho Power or separate consultants or contractors. Customer shall erect and
maintain, as required by existing conditions and performance of this Agreement, reasonable safeguards for safety and
protection, including but not limited to, posting danger signs and other warnings against hazards, promulgating safety
regulations and shall make arrangements with utilities and Dig Line to identify the location of all underground utilities 2 days
prior to commencing the Work.
5 Idaho Power shall have the right to review, test, inspect, approve, and accept the Work provided or performed by the
Customer. The Customer shall comply (and shall cause its contractors, and any person or entity performing any portion of
the Work to comply) with all federal, state, and local laws, rules, regulations, codes and permits applicable to the Work, and
the following Idaho Power specifications:
a. The minimum width of a Customer -provided trench is 18 inches for most installations. This allows adequate spacing
between conduits for most applications. Prior approval is necessary for any other width from the Idaho Power
representative assigned to this job.
b. The spoils pile will be stored a minimum of 2 feet from the edge of the trench for working space and safety.
c. The Customer will have equipment and operator onsite to correct any problems with the trench.
d. The Customer will be responsible for any damage to property or landscape done during trenching
e. The Customer will install and be responsible for erosion controls at trench location when trench is the possibility of
washing out before vegetation grows back.
f. A minimum burial depth (measured from the top of the conduit) of 42 inches for primary trench and 30 inches for
secondary and service trench. The customer will backfill with native soil and wheel -roll the trench for standard compaction
Wheel rolling achieves about 80 percent compaction rate. This depends on soil conditions. Shading the conduit with
enough selected backfill material to provide 6 inches of cover. Rocks no larger than 2 inches for the first 6 inches of fill
material are allowed and rocks no larger than 6 inches for the remainder of the fill are allowed.
g. The trench must be inspected by an Idaho Power representative prior to backfill.
Standard compaction is required in all areas that do not require high compaction. For standard compaction, backfill with the
native soil and wheel -roll the trench. If the soil is loamy or does not compact well, the spoils must be hauled off and replaced
with 3/4-inch road mix up to 12 inches of the surface. Native backfill will be used for the top 12 inches of the trench.
965 Standard Compaction footage.
Note: The grantor of the right-of-way may require high compaction in areas not under a paved surface or road but still within
the right-of-way.
High compaction is required in areas where the trench will be under a roadway, alley, driveway, parking lot (whether
paved or unpaved), a paved surface or where the grantor of the right-of-way requires high compaction. For high compaction,
backfill the trench in 12-inch lifts with %-inch road mix or pit run and compact each lift with a Wacker or other similar
compaction device. Native soil is not acceptable as a backfill material for high compaction and must be hauled off.
0 High Compaction footage.
6 The Customer acknowledges his/her full and continuing responsibility to use reasonable judgment in all aspects of the
performance of the Work. In addition, the Customer agrees that at any time during the progress of the Work and at Idaho
Power's option, Idaho Power may order, after inspection, that any Work deemed to be unsatisfactory shall be reperformed
at Customer's sole cost and expense.
7 Idaho Power will install all primary conduit, cables, transformers and pads.
8 Except for the Work described in this Agreement, all other work will be performed by Idaho Power or its contractor.
9 This Agreement and all Work required to be performed under the Work Order described above is subject to all applicable
schedules and tariffs approved and filed with Idaho Power's regulators.
10 Other
CUSTOMER TO PROVIDE TRENCH FROM BORE PIT LOCATION TO NEW PAD MOUNT TRANSFORMER
LOCATION, TRENCH MUST MEETALL REQUIREMENTS, INCLUDING BUT NOT LIMITED TO DEPTH, SPOIL
PILES, BACK FILL MATERIAL, ACCESS AND BACKFILL IS REQUIRED PRIOR TO CABLE INSTALL.
11 Public Entity Indemnity Limitation. Idaho Power acknowledges that Customer is a public entity and, as such, Customer's
liability is at all times limited as required by Idaho law, including Idaho Code Title 59, Chapter 10, the Idaho State Constitution,
and the Idaho Tort Claims Act, Idaho Code Sections 6-901 through 6-929 and any indemnification or hold harmless provision
shall be void to the extent such provision violates applicable laws. Nothing in the agreement shall be deemed to constitute a
waiver by Customer of any privilege, protection, or immunity otherwise afforded it under the Idaho Constitution, Idaho Tort
Claims Act, or any other application law or waiver of its sovereign immunity, which is hereby expressly retained.
Customer will receive credit on the Customer Cost Quo in the amount of $29,138.00, as a contribution in aid of
construction for the Work performed under this ement.
l
Customer Signature. g Date: L C;i
Idaho Power Representative
CASEY BELVOIR Date: 7/31/2026
Internal Use
Service Request: Number: 005496091 Work Order Number:':27696757 1 Design Number: 0000181333
05NOIW3305
0
#01
�1 Y' 21 \R-I-H AC9't-R/SN IXt�
C,A 25 A
B 25 B
N �H� 25 �'
05N01W3304
10
05N01W3303
10
SCOPE OF WORK
UNDERGROUND CABLE NOTES
POINT
NUMBER
FROM
TO
COHOUCTOR
CU
CABLE
SRE
CABLE
LENGTH
CONOUH
CU
CONDUT
SUE
CONDUIT
LENGTH
TRENCH
LENGTH
COMPACTIO
LENGTH
BORE
LENGTH
02
X72
PV1
DCP1K32
1100
125
DDB6
6
30
30
0
03
PV1
PV2
DCP1K32
1100
1092
DDB6
6
-
-
0
04
PV2
SY246
DCPIK32
1100
674
DDB6
6
-
-
0
05
SY246
SY197
DCP10
1110
218
DOB4
4
-
-
0
O6
SY246
SV98
DCP1 K32
1100
946
DON
6
-
-
0
15
LT97
TK149
DCP10
,—
1180
DDB2
2
965
-
-
150
15
TK149
SEC RISER
D3SC40
4/0-TRI
63
31
31
-
-
-
0
PT#1 INSTALL 50' C2 TANGENT POLE, 6" FIBERGLASS PRIMARY RISER, FAULT INDICATORS.
PT#2 TRENCH & INSTALL 6" PRIMARY FROM PT#1, INSTALL 1100 MCM, SPLICE IN VAULT, INSTALL RACKING IN EXISTING VAULT.
IN PT#3 STALL 1100 MCM IN EXISTING CONDUIT FROM PT#2, INSTALL RACKING AND SPLICE IN EXISTING VAULT.
PT#4 INSTALL PME-22 ON EXISTING VAULT, TERMINATE ALL CABLES ACCORDINGLY, INSTALL 1100 MCM IN EXISTING CONDUIT FROM PT#3, INSTALL RACKING IN VAULT.
PT#5 INSTALL b 30 PRIMARY IN EXISTING CONDUIT TO EXISTING TRANSFORMER, REMOVE EXISTING b 30 PRIMARY FROM PT#11.
PT#6 INSTALL 1100 MCM IN EXISTING CONDUIT, REMOVE 1100 MCM FROM PT#9, TERMINATE ACCORDINGLY.
PT#7 INSTALL 2- RIGID BEND, BORE ACROSS ROAD TOWARDS PT#15.
PT#8 BORE PIT FOR BORE ACROSS ROAD, INTERCEPT CUSTOMER TRENCH TO PT#15.
PT#9 REMOVE EXISTING POLE, OVERHEAD 795, DOWN GUYS, CROSS ARM & MATERIAL. 6" PRIMARY RISER, FAULT INDICATORS, 1100 MCM TO PT#6.
PT#10 REMOVE EXISTING POLE. OVERHEAD 795, TRANSFORMER BANK, OH SERVICE, CROSS ARM, & MATERIAL.
PT#11 REMOVE EXISTING POLE, OVERHEAD 795, 4" PRIMARY RISER, d URD PRIMARY TO PT#5, OH SERVICE, CROSS ARM, & MATERIAL.
PT#12 REMOVE EXSITING POLE, OVERHEAD 795, CROSS ARM, & MATERIAL.
PT#13 REMOVE EXISTING POLE, OVERHEAD 795, DOWN GUYS, CROSS ARMS, JUMPERS & MATERIAL.
PT#14 REMOVE EXISTING POLE, OVERHEAD #4 ACSR, DOWN GUYS, & MATERIAL.
PT#15 INSTALL 2" PRIMARY CONDUIT IN CUSTOMER PROVIDED TRENCH, � 10 PRIMARY CABLE, PAD MOUNT TRANSFORMER, PAD, 2" SECONDARY TO RISER ON EXISTING
POLE, TRANSFER EXISTING SERVICE RISER INTO NEW PAD MOUNT TRANSFORMER, RE -FEED EXISTING OH SERVICE.
PT#16 REMOVE EXISTING POLE, OVERHEAD 795, DOWN GUYS, CROSS ARMS, JUMPERS & MATERIAL.
PT#17-19 REMOVE EXISTING POLES, OVERHEAD 795, CROSS ARMS, & MATERIAL.
PT#20 REMOVE TANGENT CROSS ARM, INSTALL 10' FIBERGLASS DEAD END ARM, DEAD-END 795 SOUTH, INSTALL J" DOWN GUYS, ANCHORS.
PT421 REMOVE 10 DEAD END MATERIAL.
PT#22 REMOVE EXISTING POLE, #4ACSR, DEAD END MATERIAL.
CUSTOMER RESPONSIBLE FOR CUSTOMER TRENCH & COMPACTION FROM PT#8 TO PT#15, TRENCH MUST BE BACKFILLED PRIOR TO CONDUCTOR INSTALLATION.
CUSTOMER RESPONSIBLE FOR STAKING OF NEW TRANSFORMER LOCATION.
-------- EASEMENT REQUIRED PRIOR TO SCHEDULING OF CONSTRUCTION.
EASEMENT REQUIRED
9
DATE OBTAINED:
9
TO BE OBTAINED:PRIOR TO CONSTRUCTION
CUSTOMER PROVIDED TRENCH
g FROM GWC CAPITAL LLC &CITY OF EAGLE
- PRIMARY TRENCH DEPTH REQUIRES
s ♦2 OF COVER
- SECONDARY 6 SEKVICE TRENCH
[Al
We AVM CONSrRUC M
ESTIMATED
NS . DATE
2026
- ALL TRENCH SPOILS TO BE LEFT ON SITE.
-
- -- - - - - -
G EEMENT- FOR FURTHER
Inspected By:
Date:
DETAILS �•
I it
Customer Signature:
Date:
Work Order Description:
CITY OF EAGLE - 4886 HWY 16 - 3PH UG REBUILD
Feeder Name
BNLTI 1
Avian zone: 60 INCH
Arc Flash Rating: BLU E
PreBuA Dale:
Designer CLB1221
Additional DescdPtbn:
c4 Ced-Iral Cade
wueare Zone:2
Bum as Designed:
Const,-fi-Dare:
Design NQ:0000181333
RELOCATE EXISTING OVERHEAD TO UNDERGROUND
EAGLE 2050133
Joi tus.Att-t—nt:No
Operatirgvdwge:12.5KV
1
Add' et Desgi
INSTALL 86NDUCTOR IN EXISTING CONDUIT, INSTALL SWITCH ON EXISTING VAUL
stale County
cutover: NO
Work Order ReV °
Design Version:
y
.
ID ADA
coordinate5ystem:IPTM
Work OrderN0:27696757
IDAHO POWER CO. WORK ORDER MAP
SCALE: 1" =100'
Sheet 1 of 3
EASEMENT REQUIRED T98
2" BORE 25 A
DATE OBTAINED: �\ \ y o7
o \ ,
CC `SRO PME-22 J\°� TO BE OBTAINED:PRIOR TO CONSTRUCTION
FROM GWC CAPITAL LLC &CITY OF EAGLE �__
TO SY246 UT104 TO BY160 UT168 X138 : koe
— � eg
r- 'SV98
CUSTOMER TRENCH
TO FUTURE TO LT97
Sv98/— ;s B
3
ss��8r'� #10
gl A TK149
TRANSFER SERNCE RISERF
TO NEW PADMOUNT, INSTALL
NEW SEC. RISER TO FEED
EXISTING OH SERVICE
/ F174 05N01 W2801
� 60
Reiss - es Al—. P/si
\
ny
P-2-µ AcsR-P/sHM13/
\�
4 _
/
B�05i
1 /500
500
PME-22
\,
\`
1J
TO FUTURE
TO SY197
k0a '
I
SY246
v
TO X72
TO SV98 UT180
C 2u
/
\N
SY246
C
30 OPEN
/
`I
#17
Customer Signature:
k Ordsr Desalptlon:
TY OF EAGLE - 4886 HWY 16 - 3PH UG REBUILD
A
_
Feeder dame
BNLT11
H
Arm^ e: so BLUE
Am Flesh Rating: BLUE
ltional Descrlpdon:
:LOCATE EXISTING OVERHEAD TO UNDERGROUND
C' M
EAGLE
Cadasael Code Wildfire Zone: 2
2050133 aointUs. ARacnment:NO
I�i al Desal
NDUCTOR IN EXISTING CONDUIT, INSTALL SWITCH
ON EXISTING VAULT.
state County
wow: NO
IIALL
ID ADA
CGorainatesystem:IPTM
IDAHO POWER CO. WORK ORDER MAP
0
W AVM CONMUCTON I
onm
CUSTOMER PROVIDED TRENCH
- PRIMARY 1RENCH DE REWIRES
.2'OF CO
sECONMRY Y SERVICE TRENCH
DID— REOUIREs SO' OF COVER
.
P—E R-- ---C.
PERFORMED CDNSrirUCTION MURK
AGREEMENT' FOR FURTHER
i
AO BO Co
QOOOOQ QCOOOQ QOOOOQ
m M11AW C1MInW Wlh in
�CJm IOCU- LL !2!21 �Cro IO 0'
0-j }} 0 0�U-&}V 6a�ra0
O �mfn0 OR:mcn conD V10
z w Z Z I.z z 1-1 Z
LT97
PmBuIN Dale:
Built as Designed:
Construction Date:
operating voltage: 12.5KV
Work Order Revision:
SCALE: 1" =100'
Date: '
Designer CL 122
Design No: 0000181333
Design Version: 1
Work order No: 27696757
Sheet 3 of 3
•�Ra,
<5
232'
60' AmAN CONSTRUCTION
_ #18
/
OA)95 95--,,-P/4
/
n0 "103 /
ESTIMATED
ONST. DA
2026
#Is
C
I HEREBY CERTIFY THAT THE DETAILS OF THIS PLAT ARE ACCURATE TO THE
� BEST OF MY KNOWLEDGE. IOAHO POWER COMPANY (IPC) IS HEREBY
j AUTHORIZED AND REQUESTED TO INSTALL, OPERATE AND MAINTAIN ELECTRICAL
FACILITIES WITHIN THE UTILITY EASEMENTS DEPICTED ON THE PLAT. IPC WILL
NOT BE REQUIRED TO REMOVE OR RELOCATE SUCH ELECTRICAL FACILITIES
J UNLESS THE COST OF SUCH RELOCATION OR REMOVAL IS PAID IN ADVANCE
BY OR ANY SUBSEQUENT OWNER OF THE
`y 272 SUBDIVISION PROPERTY. THE UTILITY EASEMENTS SET FORTH IN THE FINAL.
RECORDED PLAT FOR THE SUBDIVISION WILL PROPERLY ENCOMPASS IPC'S
ELECTRICAL FACILITIES.
#20 /
/�
GISO# 6881870 j
Lan: 4116.457 CUSTOMER PROVIDED TRENCH
`= 05NO1W3306 Long:-116.457307
/ - PRIMARY TRENCH DEPTH REOUIRES
42- OF COVER
N - SECONDARY h JAICE TRENCH
OEI— REQV 3D- OF COVER
a0. ET7 DUP2 // cR—wEoLE°AHo oELncc �ounor+s uNE, FINAL LER, cusTO TIO
•PPERF CONSTRUCTION VIORK
FOR FURTHER
/ ALL TRENCH SPOILS TO BE LEFT ON sn-E. ETAI
a
a
Customer Signature: Date: Z e Work Order DBsal06on:
CITY OF EAGLE - 4886 HWY 16 - 3PH UG REBUILD FeederLTI 1 Ahan lone: 60 INCH Des
BNLT11 An, RathRatl BLUE Date: gnenCL 12
Additional Descri - ^9 Cw as Designed:
RELOCATE EXISTING OVERHEAD TO UNDERGROUND °"'' Cadastra20501 33ode ointU.AtB:2 consnDeDnDate: De�gnNo: 0000181333
EAGLE 2050133 Joint U. Altachment:NO Design Version:I
e stare County cutoYer: NO Work Ord rRwisj 12.5KV
R tE MNDUCTOR IN EXISTING CONDUIT, INSTALL SWITCH ON EXISTING VAULT. ID ADA Coordinate system:IPTM W°" O°°rR°YI°°"' Work Order No:27696757
m
IDAHO POWER CO. WORK ORDER MAP SCALE: 1" =100' Sheet 2 of 3
m
�low
PW
Customer Consent to proceed with Engineering/Design
Requiring Pre -Paid Engineering Fees
Thank you for your request. We are excited to serve as your electric service provider.
I, Gi 4/ G y l-�s/e
("Applicant") requested for Idah0 P
ower Company ("Idaho Power,,
to proceed with engineering for the work request located at:
Idaho Power's line extension tariff provides:
4886 HIGHWAY 16
EAGLEAD ID 83616
Engineering Charge. Applicants or Additional Applicants will be required to prepay all engineering costs
for Line Installations and/or Alterations greater than 16 estimated hours. Estimates equal to or less than
16 hours will be billed to the Applicant or Additional Applicant as part of the construction costs, or after the
engineering is completed in instances where construction is not requested.
I understand I am responsible for an engineering charge of $97.00 per hour in Idaho or $96.00 per hour
in Oregon. 1 agree to pay the engineering charge, whether or not the work requested is built, and I
understand the engineering charge is non-refundable.
Additional fees may include, but are not limited to, the following: right of ways, permitting, research
related to the design and design changes requested by the customer and billed as a part of the
construction costs.
The engineering hourly rate will update annually and is assessed beginning on the Public Utility
Commission's approved date.
Engineering Charge S4,074.00
Permit Charges
Total amount to be paid and received prior to job being$0.00
quoted $4,074,00
PLEASE PRINT, COMPLETE AND SIGN, THEN SEND WITH PAYMENT TO:
Idaho Power Company
10790 Franklin Rd
Boise, ID 83709
Attn: ZACH BIANCHI
Important to fill out this section to avoid delays designing this project
Financially Responsible Name:
Email Address: C z
E1N or last 4 of SSN: o0J v 3 o y 3 S
Financially Responsible Signature Date:
Phone: < ,; 7-
,
Idaho Power Representative: ZACHARY BIANCHI
Date: 1 /8/2026
Email Address: ZBianchi@idahopower com
APPROVE
AMOUNT PA / "1
ACCOUNT*
CHECK #:
DATE:
Phone: (208) 388-5118
FILED
CITY OF EAGLE
JAN 2 7 2026
File:
Route to: